Construction Contract Example

plantilla imagen principal
Haga clic en la imagen para ampliar / Haga clic en el botón de abajo para ver más imágenes

Guardar, completar los espacios en blanco, imprimir, listo!
Looking for a construction contract template? Download this Construction Contract example in Microsoft Word will help you out!

Vandaag: USD 3.98 Descárgalo ahora


Tarjetas de crédito procesadas por PayPal/Mollie

Formatos de archivo premium disponibles:


  • Este documento ha sido certificado por un profesionall
  • 100% personalizable

legal Legal construction contract contrato de construcción construction contract sample muestra de contrato de construcción example construction contract ejemplo de contrato de construcción how to make a construction contract cómo hacer un contrato de construcción construction construcción agreement with contractor acuerdo con el contratista construction contractor agreement contrato de contratista de construcción

Looking for a construction contract template? Download this Construction Contract template in Microsoft Word. As you will see, it will help you out!

Before you showcase the first wall of your next construction renovation or project, you should sign a Construction Contract to protect yourself and your company in the case of delays, cost overruns, or other general mishaps.  
If you're hiring the contractor or construction firm, customize this template to outline how for example weather delays and material shortages are handled, when and how much you'll be paying for this service, and when you want the workers to show up each day.

When do you need to use this Construction Contract document?

  • You are a contractor in charge of building or renovating a property.
  • You are hiring a contractor to build or renovate your property.

What articles should be included?

  • Parties
  • Witnesseth
  • Hold Harmless
  • Assignment of Contract
  • Change Orders
  • General Guarantee
  • Lien Waivers
  • Permits and Codes
  • Work Performance
  • Condition of Premises
  • Use of Utilities
  • Use of On-Site Loam
  • Inspection
  • Right to Stop Work
  • Payment Schedule
  • Contract Security
  • Contract Security (In lieu of conventional performance and payment bonds)
  • Liquidated Damages
  • Taxes
  • Arbitration
  • Governing Law
  • Retention of and Access to Records
  • Conflict of Interest
  • Signatures
(All articles are included in this Construction Contract)

Misunderstandings happen often on construction projects, but when all of the details are outlined in a construction contract, it makes everyone's lives easier. A construction contract is also known as a construction agreement. 

Download this Construction Contract and after downloading you can craft and customize every detail of this construction contract very quickly.

Nada en este sitio se considerará asesoramiento legal y no se establece una relación abogado-cliente.

Deja una respuesta. Si tiene preguntas o comentarios, puede colocarlos a continuación.

default user img

Plantillas relacionadas

Plantillas más recientes

Temas más recientes

Lee mas